NOTICE TO RECEIVE SEALED BIDS BID #2021-25 The City of Apalachicola will receive sealed bids from any qualified person, company or corporation interested in constructing: City of …

Posted

NOTICE TO RECEIVE SEALED BIDS

BID #2021-25

The City of Apalachicola will receive sealed bids from any qualified person, company or corporation interested in constructing:

City of Apalachicola Landscaping

This project includes miscellaneous landscaping between SR 30 (US 98) from Market Street to the 8th Street with plantings at entrance signs at the eastern base of the bridge westbound from Eastpoint and western entrance sign at 26th Avenue. Project includes plantings, installation and maintenance.

Plans and Specifications can be obtained at 192 Coach Wagoner Blvd. Apalachicola, FL 32320 or on our website at www.cityofapalachicola.com. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. If you have any questions please contact Leo Bebeau at lbebeau@cityofapalachicola.com or call at (850)653-9319.

Completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.

Please place YOUR COMPANY NAME, SEALED BID and the BID NUMBER on the outside of your envelope and include the original bid plus 3 copies and an electronic copy...

Bids will be received until 4:00 p.m. Eastern Time, on Friday, December 17th , 2021 at the City of Apalachicola, 192 Coach Wagoner Blvd, Apalachicola, Florida 32320, and will be opened on Monday, December 20, 2021 at 9:00 a.m. Eastern Time.

All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.

The City of Apalachicola reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City.

CITY OF APALACHICOLA

FRANKLIN COUNTY, FLORIDA

Brenda Ash, Mayor

Publish Dates: November 18 & 25, 2021

Comments

No comments on this item Please log in to comment by clicking here